Ecommerce development contract template

This agreement is made on [Date] between [Your Name / Business Name] (the "Contractor") and [Client Name / Company] (the "Client").

The Contractor is an independent contractor, not an employee of the Client.

The Contractor will build an online store on [platform] including: [theme customization or custom theme, up to [number] products migrated, payments, shipping, and tax configuration, and the apps listed here: [list]].

Product photography, copywriting, and marketing campaigns are not included unless listed. Platform and app subscription fees are the Client's.

Work is delivered in milestones, each reviewable on a staging store with [5] business days for feedback and [2] revision rounds within the agreed scope.

Migrated data (products, customers, orders) is verified by documented spot-checks against the source. The Client signs off on the staging store in writing before cutover; the old store is not switched off without that sign-off.

A [30] day bug-fix window follows launch. New features requested after launch are new work.

The total fee for the work is [Amount]. A non-refundable deposit of [Amount or %] is due before work begins, and the balance is due [on delivery / per the schedule below].

Invoices are payable within [14] days. Late payments may incur a fee of [1.5%] per month on the outstanding balance.

Any expenses (stock assets, plugins, printing, travel) are billed to the Client at cost and agreed in advance.

Work outside the scope described above is not included. If the Client requests additional work, the Contractor will provide a written estimate, and that work begins once the Client approves it in writing.

The Client will provide all content, access, feedback, and approvals needed to complete the work, in a timely manner.

If the project is delayed by more than [30] days due to a lack of Client response or materials, the Contractor may pause the project and invoice for work completed to date.

Custom theme code written for this project transfers to the Client on final payment. Third-party apps, themes, and platform services remain under their own licenses, purchased in the Client's name.

The Contractor retains the right to reuse general techniques and non-client-specific code.

Product data, images, and content belong to the Client. The Contractor may show the store in a portfolio unless asked otherwise in writing.

Each party will keep the other's confidential information private and use it only to carry out this agreement.

The Contractor may show the finished work in a portfolio or case study unless the Client asks in writing to keep it private.

Either party may end this agreement with [14] days written notice. If the Client cancels, the deposit is non-refundable and the Client pays for all work completed up to the cancellation date.

If the Contractor cancels, any pre-paid amount for work not yet delivered is refunded.

The Contractor's total liability under this agreement is limited to the total fees paid by the Client. Neither party is liable for indirect or consequential losses.

The work is provided without warranties beyond those stated here.

The Contractor controls how and when the work is done, uses their own tools, and is responsible for their own taxes and insurance. Nothing here creates an employment, partnership, or agency relationship.

This agreement is governed by the laws of [Your State / Country]. Any dispute will be handled in the courts of that location.

Contractor: ______________________________ Date: ____________

Client: __________________________________ Date: ____________